Status of LOAs issued to power utilities by CIL sources (As on ) (Provisional) Qty. For Which MoU Is Signed (Mt)

Transcription

1

2

3

4 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), Budge Budge Extn., Pujali, Budge Budge, South 4 Pg, W.B. ( 3) BCCL DVC Mejia TPS Phase-, no.-8 (Tapering) BCCL All milestones. FSA cannot be executed as the name of the TPP does not feature in the list of PUs/PPs of MOC letter dated Achieved 3 Maithan Right Banks TPS ( 1), Dhanbad, Zharkand 1/ BCCL Paricha Extn, UPRVUNL ( 5&6), U.P BCCL V V 5 Raghunathpur TPS, West Bengal (Tapering) BCCL are under. LOA Still valid 6 Ragunathpur TPS,Stage -1, DVC,Ragunathpur, Purulia,West Bengal (Tapering Linkage) (Tapering) CCL Milstones related to Water allocation, COD, Syncronization, 90% Land acquisition, Financial Closure not. Milestone related to Forest Clearance not yet submitted. Deficiencies in milestones has alredy been communicated to unit. LOA Still valid 7 Adhunik Power & Natural Resources Ltd., Helasong, Chandil, Kandra, Distt: Saraikela Kharsawan, Jharkhand ( 1) (Tapering) CCL Adhunik Power & Natural Resources Ltd., Helasong, Chandil, Kandra, Distt: Saraikela Kharsawan, Jharkhand ( ) (Tapering) CCL * at 50% trigger level. FSA executed (OLD) 9 Bajaj Hindusthan Ltd.,Barkhera Dist:Pilibhit, U.P ( 1&) CCL Bajaj Hindusthan Ltd.,Khamberkhera Dist:Kheri, U.P ( 1&) CCL

5 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), Bajaj Hindusthan Ltd.,Kundarki Dist:Gonda, U.P ( 1&) CCL Bajaj Hindusthan Ltd.,Maqsoodpur Dist:Shajahanpur, U.P ( 1&) CCL Bajaj Hindusthan Ltd.,Utraula Dist:Balrampur, U.P ( 1&) CCL Barh TPS ( 1, & 3), Patna, Bihar CCL All milestones. The unit has been advised to execute FSA Achieved 15 Bina TPP, Bina Power Supply Ltd., MP ( 1&) CCL FSA executed.both units already commssioned Bokaro TPS-A (DVC), Bokaro, Jharkhand ( 1) CCL Milstone for 90% Land acquisition, Financal Closure, Water allocation, Forest Clearance and Environment Clearance not LOA Still valid 17 Corporate Power Ltd, Chitarpur,Distt: Latehar Jharkhand ( 1&) CCL All Prescribed milestones. Physical inspection of the plant was carried out on has submitted Mid-term PPAs with DSCOM valid till June 016. FSA not executed yet due to non submission of Long Term PPAs with DSCOMs (as directed by letter dtd ) Achieved 18 Harduaganj Extn. ( 8&9), U.P CCL /1/ FSA executed. Both units already commssioned. V X 19 Jhajjar Thermal Power Project (Case- ),Vill. Jharli, Jhajjar Dist., Haryana ( 1&) CCL Maithan Right Banks TPS, Dhanbad ( ) 1/ & CCL 55 6/

6 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), Nabinagar TPS (Joint Venture of NTPC & B.S.E.B), Bihar Bulk Tendering CCL All milestones. Achieved Nabinagar TPS, Bihar (Joint Venture of NTPC & Railway) ( 1-4) CCL The unit has all the milestones except firm water allocation. the unit has submitted documents in respect of firm water allocation through on i.e. after valadity period of LOA. Further, unit has represented within the valadity period of LOA for extension of LOA for three months under Force Majeure clause of LOA V 3 NCPP, Dadri, Stage-, Gautambudh Nagar, UP ( 5&6) CCL Drawing coal under MoU.Both units already commissioned. Did not respond for execution of FSA despite of several letters of CCL V V MOU signed 4 Raghunathpur TPS stage, W.B. (Bulk Tendering) Bulk Tendering CCL / All milestones. 5 Rosa Power Supply Co. Ltd, TPS Phase -, Rosa, Dist. - Shahjahanpur, UP ( 3&4) CCL V 6 Bongaigoan TPS ( 1&) ECL 500* are under verification LOA Still valid 7 Bongaigoan TPS, (Pre NCDP LOA) ( 3) ECL All except Syncronisation and COD Achieved 8 Budge Budge Extn. -, Pujali, Budge Budge, South 4 Pg, W.B. ( 3) ECL 50* Durgapur Steel TPS (DVC), Durgapur, West Bengal (Pre NCDP LOA) ( 1&) ECL MoU for signed for both unit. Transfer of source of coal for one unit of 500 MW from ECL to BCCL is under process. MOU signed 30 Farakka TPS, Stage, NTPC, Farakka, & West Bengal (Pre NCDP Linkage) ( 6) ECL Drawing Coal under MoU. Advised for signing of FSA V MOU signed

7 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), Kahalgoan TPS, Stage, Phase, Kahalgoan, Bihar (Pre-NCDP Linkage) ( 7) & ECL Drawing Coal under MoU. Advised for signing of FSA V MOU signed 3 Mejia TPS (Phase ), DVC, Mejia, Bankura, West Bengal ( 1) (Tapering) ECL MoU signed. Clearification regarding coal block is required under tapering linkage policy MOU signed 33 Muzaffarpur TPP, Stage, Kanti Bijli Utpadan Nigam Ltd, Kanti, Muzaffarpur, Bihar ( 1&) ECL Milestone document regarding land incomplete. has been informed under 34 deal Energy Projects Ltd., Bela, Nagpur, Maharashtra ( 1) MCL 70* and PPA not submitted. COD not. PPA is not with DSCOMs Achieved 35 Videocon ndustries Ltd (name changed to CPVPL) MCL ice issued for cancellation of LOA. Matter sub-judiced. ice issued for cancellation. Matter subjudice 36 Adani Power Ltd., Mundra, Gujarat ( 1, & 3), Maharastra MCL Surrendered the option of imported coal. 37 Bellary TPS, KPCL, Bellary, Karnataka ( ) (Tapering) MCL * MOU signed on and same was valid till on a/c og tapering policy. Supply stopped. validity over on Bhavanpaddu TPP (East Coast Energy Pvt. Ltd.,) Begampet, Hyderabad MCL schieved. COD from MOP not received. PPA not submitted 39 Bhusawal TPS, MAHAGENCO ( 4&5) MCL FSA for unit#4 is not effective for want of CPs. V V 40 GMR Kamalanga Energy Ltd., Phase-, Kamalnga, Dhenkanal ( 1) MCL for 45 MW out of 500 MW as per capacity covered under PPA

8 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), GMR Kamalanga Energy Ltd., Phase-, Kamalnga, Dhenkanal ( ) (Tapering) MCL Normal milestones. 4 Haldia TPP, Haldia Energy Ltd. Phase-, Sutahata Railway Station, Haldia ( 1&) MCL All milestones. COD from MOP not received, only 1 appears in MOC list upto nd-barath Energy (Utkal) Ltd., Hyderabad ( ) MCL , COD not received from MOP. PPA submitted for part capcity nd-barath Energy (Utkal) Ltd., Hyderabad, COD not received from MOP. PPA submitted for part MCL ( 1) capcity. 45 nd-barath Power(Madras) of M/s nd- Barath-infra (P) Ltd MCL are under verfication. Clearification on location was received from MOC on ndia Bulls Nasik TPP of M/s. ndia Bulls realtech Ltd., Sinnar, Dist. Nasik, Maharashtra, Phase- ( 1-5) MCL All milestones. PPA not submitted. COD from MOP not recevied V 47 ndiabulls Amravati TPP, Dist Amravati Maharashtra of ndia Bulls Power Ltd., Phase- ( 1-5) MCL All milestones expect COD and Synchronisation : V-V 48 Jhabua Power Ltd. Barela- Ghorkhpur, Seoni, MP ( 1) MCL 300* as per capacity covered under PPA Jhajjar TPS, Haryana (A JV of HPGCL and NTPC) ( 1, & 3) (APCPL/GSTPP) MCL & Part quantity is being transferred to ECL/NCL. Drawing coal under MoU. Advised to execute FSA MOU signed 50 Jindal ndia Thermal Power Ltd., Derang TPP, Odisha ( 1) (Cap 1X600 MW) MCL FSA executed for 7 MW as per PPA. Configuration changed to 1X600 MW. LOA dtd clubbed Jindal ndia Thermal Power Ltd., Derang TPP, Odisha ( 1) (Cap 1X600 MW) MCL FSA executed for 7 MW as per PPA. Configuration changed to 1X600 MW. LOA dtd clubbed

9 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), Jindal Power Limited, Tamnar, Raigarh, Chhattisgarh MCL 100* Clarification required regarding EC. 53 Khaperkheda TPS, MAHAGENCO ( 5) MCL V 54 KodermaTPS, DVC ( 1&), Jharkhand MCL on in modified model for Power Houses. Become effective from Jan'13 for 1 unit. But due to non achievement of COD within 1 months of expected date. ice issued for cancellation Kothagudam-V, APGENCO ( 1) MCL Krishnapatanam TPS, APGENCO ( 1) MCL Board resolution & status of net worth not submitted. Further, project being implemented by APPDCL,whereas LOA was in name of APGENCO KVK Nilachal Power Pvt. Ltd, Kandarei, Cuttack Dist., Orissa ( 1) MCL enhanced to 300MW (50 MW is pre-ncdp).ii)documents submitted for 350 MW.iii)Forest clearance not submitted.iv)ice issued for cancellation.matter sub-judice ice issued for cancellation matter subjudice 58 KVK Nilachal Power Pvt. Ltd, Kandarei, Cuttack Dist., Orissa ( 1) MCL enhanced to 300MW (50 MW is pre-ncdp) but documents submitted for 350 MW.iii) Forest clearance not submitted.iv)ice issued for cancellation.matter sub-judice ice issued for cancellation matter subjudice 59 KVK Nilachal Power Pvt. Ltd, Kandarei, Cuttack Dist., Orissa ( &3) MCL enhanced to 300MW (50 MW is pre-ncdp) but documents submitted for 350 MW.iii) Forest clearance not submitted.iv)ice issued for cancellation.matter sub-judice LANCO Group Ltd., Phase-, Babandh Village, Dhenkanal, Odisha. (1X660 MW) MCL ice issued for cancellation but letter dt advised not to take any coercive action ice issued for cancellationmo C advised not to take coercive action

10 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), Meenakshi Energy Pvt. Ltd., Hyderabad MCL All milestones except COD & Synchronization. Surrenderded mport option. 6 Mettur TPS, TANGEDCO ( 1) & MCL Mouda TPS, Nagpur, Maharastra ( 1) MCL At present Rail link is not available. MOU signed 64 Nava Bharat Power Pvt. Ltd., Hyderabad. (Tapering) & MCL ice issued for cancellation.matter sub-judiced. ice issued for cancellation. Matter subjudice 65 NCC Vansadhara Mega Power Projects of Nagarjuna Constuction Co. Ltd., Hydreabad MCL are under in consultation with SECL. 66 NCC Vamsadhara Mega Power Project of M/s. Nagarjuna Construction Co. Ltd., Sompeta, Dist: Srikakulam, A.P. (PP) 70% level for Coastal TPS) ( 1&) MCL (Transferred from SECL) 130* LOA from SECL for part quantity has been transferred to MCL. are under in consultation with SECL. 67 North Chennai Extn. TPP (Stage-), TANGEDCO ( 1) MCL would be as per SLC (LT) decision dated North Chennai, TPS, TANGEDCO ( ) & MCL would be as per SLC (LT) decision dated NSL Nagapatnam Power & nfratech Pvt. Ltd., Hyderabad & MCL Final MOEF Clearance submitted after validity. Final water allocation not submitted. Document for start of construction submitted earlier were not in order. Proper documents submitted beyond validity period. 70 NTPC,Mouda Extension,Dist- Nagpur,Maharastra Bulk Tendring MCL Land- Sale/Lease deed not submitted but possession letter submitted.

11 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), NTPC,Solapur, Maharastra Bulk Tendering MCL All milestones. 7 Painapuram TPP, Thermal Power Tech Corpn. Ltd. ( 1&) MCL Only unit 1 apperas in MOC list upto PPA not submitted Paras Expn.- TPS, MAHAGENCO MCL Parli - TPS, MAHAGENCO MCL PEL Power Limited(an SPV of Patel Engineering Limited) Amreli, Gujrat MCL nvestment decision and DPR submitted for different capcity 3X350MW but LOA issued for 500 MW.Application for change of configuration has been forwarded to MOP for comments.mop gave NOC for change in size from 500 MW to 350 MW. Environment clearance is for imported coal. Financial closure is in-principle, no document for start of constrn. vide letter dt advised not to take any coercive action. advised not to take any coercive action 76 Raichur TPP, KPCL Karnataka ( 8) MCL Surrendered import option V 77 Raj West Power Ltd of JSW Energy Ltd. (Tapering) MCL * Linkage was granted upto March 01 only. LoA is not valid anymore.bg returned. LoA terminated 78 Rajiv Gandhi Thermal Power Plant, Khedar, Hissar (Earlier Hissar TPS) ( 1) (Cap. 1X600 MW) MCL Drawing coal under MoU. Requested to sign FSA MOU signed 79 Rajiv Gandhi Thermal Power Plant, Khedar, Hissar (Earlier Hissar TPS) ( ) (Cap. 1X600 MW) MCL Drawing coal under MoU. Requested to sign FSA MOU signed 80 Rayalseema TPS Stage-, Kadapa ( 5) MCL but yet not effective for want of completion of CPs V

12 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), Rayalseema TPS Stage-, Kadapa ( 6) MCL Addl. CG was not given for late submission of documents. 8 Simhadri Expansion Stage- Phase- Visakhapatnam ( 4), A.P MCL Drawing coal under MoU. V MOU signed 83 Simhadri TPS Expn., Vishakhapatnam, A.P. ( 3) MCL Drawing coal under MoU MOU signed 84 Sterilite Energy Ltd (SEL) (Phase-1), Jharsuguda, Orissa ( ) MCL Advised to sign FSA in modified model Sterlite Energy Ltd. (1000 MW on tapering basis) ( 1, 3 & 4) (Tapering) MCL * All for units in old model having 50% trigger level. PPA not with DSCOMs : V FSA executed (OLD) 86 Talwandi Sabo Power Ltd., PSEB, Pansa, Talwani, Sabo, Bhatinda, Punjab ( 1, and 3) MCL All milestones. COD received for all 3 units but only units appears in MOC list dated PPA submitted. Claraification on ownership change required : 87 Tutticorin TPS, NLC Tamilnadu Power Ltd. ( 1&) & MCL Forest clearance-.noc from forest authority is required. COD and Synchronization not yet submitted. MOC letter dated advised not to take corevice action Vallur TPS Phase-, (NTECL) (A JV of NTPC and TNEB ) ( 3) MCL Land doc submitted for less than 90%. Forest clearance not submitted Vallur (Earstwhile Ennore) TPS (NTECL) (A JV of NTPC and TNEB ) ( 1&), Tamilnadu MCL Drawing coal under MoU. Advised to sign FSA MOU signed 90 Vijayawada-V, (1) MCL but not yet effective for want of achievement of CPs V

13 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), Vishakapatnam TPS of HNPCL, A.P. / (Ractification) MCL * in prior model with 50% trigger level which is not yet effective. FSA executed (OLD) 9 Bara TPS (UPPCL) / Prayagraj Power Generation Ltd NCL have been Karchana TPS (UPPCLP) Sangam Power Generation Ltd NCL have been. 94 Anpara-D TPS, UPRVUNL, ShaktiBhawan, Ashok Marg, Lucknow, UP NCL Anpara-D TPS, UPRVUNL, ShaktiBhawan, Ashok Marg, Lucknow, UP NCL Still valid LOA Still valid 96 D.B.Power Ltd.,Deosar,Sidhi NCL All milestones have been. included in the MOC Letter deted Lanco-Anpara Power Ltd. Anpara, Dist.Sonebhadra, U.P. (Linkage for 1000 MW + 00 MW, ( 1&) NCL (x500 MW revised to x600 MW). 98 Obra Extn, Phase-1, (UPRVUNL), Sonebadhra, UP NCL * Following were not pertaining to 500 MW TPS: 1. Land Acquisation towards 18 mths & 4 mths.. Environment Clearance towards 1 months. 3. Forest Clearance towards 4 months. 4. Commitment of Equity investment towards 18 months and 5. Financing of the project/ Financial Clousere towards 4 months timeline have not been submitted. However, no document regarding completion of milestones towards 660 MW has been submitted by UPRVUNL. As Such, CG was surrendered for encashment for which UPRVUNL has filed a case. Case is subjudice in the High Court, Lucknow Bench CG Forfeited and matter subjudiced. 99 Rihand Phase- NTPC, Sonbhadra, U.P. ( 5) NCL NTPC is not agreeing with incorporation of the clause no.13 pertaining to"in principle" agreement to implement CL's 'Source Specific' policy as such, they are not signing FSA V-V

14 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), Rihand STPS St., Bijpur, Sonebhadra, U.P. level) Phase-, Sonbhadra, U.P. ( 6) NCL NTPC is not agreeing with incorporation of the clause no.13 pertaining to"in principle" agreement to implement CL's 'Source Specific' policy as such, they are not signing FSA V-V 101 VSTPP,Stage-V ( 11&1), Singrauli. M.P NCL NTPC is not agreeing with incorporation of the clause no.13 pertaining to"in principle" agreement to implement CL's 'Source Specific' policy as such, they are not signing FSA X-X 10 Bongaigoan TPS ( 1&), Assam NEC are under LOA Still valid 103 Adani Power Maharshtra Ltd.,TPS Phase- (x660 MW), Vill. Tiroda, Dist. Gondia, Maharashtra, (Captive Block for 800 MW & LoA for 1180 MW) ( 1&) SECL Adani Power Maharshtra Ltd.,TPS Phase- (x660 MW), Vill. Tiroda, Dist. Gondia, Maharashtra, (Captive Block for 800 MW & LoA for 1180 MW) ( 1&) SECL (Transferred from WCL) 1180* Transferred from WCL Adani Power Maharshtra Ltd.,TPS Phase- (x660 MW), Vill. Tiroda, Dist. Gondia, Maharashtra, (Captive Block for 800 MW & LoA for 1180 MW) ( 1&) (Tapering) SECL All milestones except COD & synchronization Adani Power Maharshtra Ltd.,TPS Phase- (x660 MW), Vill. Tiroda, Dist. Gondia, Maharashtra, (Captive Block for 800 MW & LoA for 1180 MW) ( 1&) (Tapering) SECL (Transferred from WCL) 140* Transferred from WCL Adani Power Maharastra Ltd., Village Tiroda, Distt. Gondia, Maharastra ( 3) (Tapering) SECL All milestones except COD & synchronization. 108 Anuppur TPP, MB Power Limited, Mouhari, Anuppur Dist., M.P. ( 1&) SECL FSA yet to be effective

15 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), Athena Chhattisgarh Power Ltd., Singhitarai Thermal Power Project, Singhitarai, Distt. Champa Janjgir, Chhattisgarh SECL Action is being taken as per the decision of dated where change in capacity to 1X600 MW is to be accepted, LOA holder is required to get the approval of MOC for change of name/spv and also to clarify documents submitted against milestone & 8. A reply to letter received from MOC vide 301/35/009-CPD Dated regarding change of name is being sent to MOC. 110 Bharat Aluminium Compnay Limited, Balco Nagar, Distt: Korba ( 1&) SECL All milestones except COD & synchronization. 111 Bina TPP, Bina Power Supply Ltd., MP ( 1&) SECL 500* FSA yet to be effective Chabra TPP, Extn. Project, Phase-, RRVUNL, Choki Motipura Village, Tehsil Chhabra, Baran Distt., Rajasthan ( 3&4) (X50 MW) (Tapering) SECL All milestones except COD & synchronization. 113 Chabra TPS, RRVUNL, Chhabra TPS, Chowki, Motipura, Teh. Chhabra, Distt. Baran, Rajasthan ( 1&) (X50 MW) SECL / Chhattiasgarh Power Ventures Private Limited (CPVPL) (Fromerly Videocon ndustries Ltd.), Gaud/Champa, Janjgir, CG SECL 660* Only copy of a letter addressed to MCL in response to MCL letter along with some documents have been received in SECL. No communication to SECL or reply to SECL letters regarding deficient milestones and/or Addl CG has been received so far. LOA Still valid 115 DB Power Ltd., Janjgir, Champa Dist, Chhattisgarh 90% level for 600 MW on permanent basis & 600 MW on tapering basis SECL All milestones except COD & synchronization. 116 DB Power Ltd., Janjgir, Champa Dist, Chhattisgarh 90% level for 600 MW on permanent basis & 600 MW on tapering basis SECL (Transferred from MCL) 100* Transferred from MCL 117 Dhariwal nfrastructure (P) Ltd., Maharastra (Additional capacity) (x70 MW revised to x300 MW. LoA under NCDP for 70 MW & 90% level for 330 MW) ( ) SECL All milestones except COD & synchronization

16 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), Dhariwal nfrastructure (P) Ltd., Maharastra, Phase-, Maharastra ( 1) SECL All milestones except COD & synchronization Dheeru Powergen Pvt. Ltd. (Phase-) Village Churri, Kotgora Division, Chhattisgarh ( 1) SECL ice for cancellation/withdrawal of LOA and encashment of CG was issued. All milestones not within LOA validity. However, MOC had earlier advised not to take coercive action and as per SLC (LT) MOM dated , unresolved milestones issues are to examined in next SLC (LT) meeting. Further, the updated status has been conveyed to MOC vide letter SECL/BSP/S&M/COMM/386/DPGPL/657 dated 30/0.03/ advised not to take any coercive action Dheeru Powergen Pvt. Ltd., Korba, 10 Chhattisgarh level) ( SECL &3) ice for cancellation/withdrawal of LOA and encashment of CG was issued. All milestones not within LOA validity. However, MOC had earlier advised not to take coercive action and as per SLC (LT) MOM dated , unresolved milestones issues are to examined in next SLC (LT) meeting. Further, the updated status has been conveyed to MOC vide letter SECL/BSP/S&M/COMM/386/DPGPL/657 dated 30/0.03/ advised not to take any coercive action 11 EMCO Energy Ltd. an SPV of GMR Energy Limited (Formerly EMCO Energy Ltd.), Warora, Dist: Chandrapur, Maharashtra SECL 70 18/ FSA yet to be effective EMCO Energy Ltd. an SPV of GMR Energy Limited (Formerly EMCO Energy Ltd.), Warora, Dist: Chandrapur, Maharashtra SECL All milestones except COD & synchronization deal Energy Projects Ltd., Bela, Nagpur, Maharashtra ( 1) SECL 70* All milestones except COD & synchronization ndiabulls Amaravati TPP of ndia Bulls Power Ltd., Nandgaonpet, Dist: Amravati, Maharashtra, Phase- ( 1-5 ) (5X70 MW) SECL FSA yet to be effective V 15 ndiabulls Amaravati TPP of ndia Bulls Power Ltd., Nandgaonpet, Dist: Amravati, Maharashtra, Phase- ( 1-5 ) (5X70 MW) SECL (Transferred from WCL) 1350* One time release of 50,000 tonnes supplied. Transferred from WCL V 16 ndiabulls Nasik TPP of ndia Bulls Realtech Ltd., Sinnar, Dist. Nasik, Maharashtra (PP) Phase- ( 1-5) (5X70 MW) SECL 1350* 08/ All milestones except COD & synchronization V

17 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), ndiabulls Nasik TPP of M/s. ndia Bulls Realtech Ltd., Sinnar, Dist. Nasik, Maharashtra (PP) Phase- ( 1-5) (5X70 MW) SECL (Transferred from WCL) 1350* All milestones except COD & synchronization. Transferred from WCL V 18 ndiabulls Nasik TPP of M/s. ndia Bulls Realtech Ltd., Sinnar, Dist. Nasik, Maharashtra (PP) Phase- ( 1-5) (X300 MW changed to 1X600 MW) SECL All milestones except COD & synchronization : V-V 19 Jhabua Power Ltd. (Formerly Kedia Power Ltd.), MP ( 1) SECL / This LOA clubbed with LOA dated for 1x600 MW Jhabua Power Ltd. (Formerly Kedia Power Ltd.), MP ( 1) SECL All milestones including special milestones (except synchronization & COD) within overall validity period of LOA for 1x600 MW. As per 16th CLOA, quantity of 1.87 mtpa on SECL for 1x600 MW has been approved. This LOA clubbed with LOA dated 01/ for 1x300 MW. Configuration changed to 1X600 from X Jindal Power Limited, Tamnar, Raigarh, Chhattisgarh (X600 MW) SECL Achievement of milestones related to land and construction/commissioning of plant is not clear. Clarification in this regard has been asked from MOC. 13 Kalisindh TPP, RRVUNL, Nimoda Village, Jhalawar Distt., Rajasthan (Tapering) ( 1) SECL All milestones except COD & synchronization. 133 Korba STPS (Stage-) (NTPC) ( 7) / & SECL For the of All milestones V MOU signed 134 Korba West Power Co Ltd., (Phase-), Raigarh, Chattisgarh ( 1) (X300 changed to 1X600 MW) SECL All milestones.this LOA clubbed with LOA dated for 1x600 MW Korba West Power Co Ltd., (Phase-), Raigarh, Chattisgarh ( 1) (X300 changed to 1X600 MW) SECL All milestones except COD & synchronization for 1x600 MW. As per 16th CLOA, quantity of.496 mtpa on SECL for 1x600 MW has been approved. This LOA clubbed with LOA dated for 1x600 MW Korba West TPS Extn., CSPGCL ( 5) / & SECL FSA yet to be effective V

18 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), Kota TPS, RRVUNL, Kota Thermal Power Station, Sakatpura, Kota, Rajasthan ( 7) SECL / V 138 KSK Mahanadi Power Co. Ltd. (Formerly Wardha Power Co. Pvt. Ltd.), Narihyara, Janjgir, Champa, chhattisgarh 90% level on Tapering basis) ( 1, & 3) SECL All milestones. Quantity 1 LTPA through MOU for precommissioning, carpeting trial run has been released. 139 Lanco Power Limited (Formerly Lanco Amarkantak Power Limited), Pathdi, Distt. Korba, Chhattisgarh ( ) SECL / form P&P deptt All milestones. Drawing coal under MoU MOU signed Lanco Power Limited (Formerly Lanco 140 Amarkantak Power Ltd.), Pathadi, Korba, SECL All milestones except COD & synchronization V Chhattisgarh ( 3&4) 141 Lanco Power Limited TPS-Phase- (Formerly Lanco Amarkantak Power Ltd.), Pathadi, Korba, Chhattisgarh ( 3&4) SECL All milestones except COD & synchronization V 14 Lanco Vidarbha Thermal Power Limited, Village Mandva, Pulai and Belgaon, Distt. Wardha, Maharastra ( 1) SECL All milestones except COD & synchronization. However, Following issues are to be resolved:- 1. Defualt in submission of Addl. CG..Vide letter dated submitted on , it is mentioned that LVTPL is an SPV of Lanco nfratech Ltd. (LTL). This needs conformation from MOC. 3. Mode of coal transportation as per MOEF is only washed coal by Rail. Confirmation/clarification from MOEF in this regard is required Lanco Vidarbha Thermal Power Limited, Village Mandva, Pulai and Belgaon, Distt. Wardha, Maharastra ( ) SECL All milestones except COD & synchronization. However, Following issues are to be resolved:- 1. Defualt in submission of Addl. CG..Vide letter dated submitted on , it is mentioned that LVTPL is an SPV of Lanco nfratech Ltd. (LTL). This needs conformation from MOC. 3. Mode of coal transportation as per MOEF is only washed coal by Rail. Confirmation/clarification from MOEF in this regard is required Maruti Clean Coal and Power Limted, Bandakhar, Korba, Chhattisgarh ( 1) SECL All milestones except COD & synchronization.however, clarification regarding source of supply in MOEF is required Marwa TPS, CSPGCL, Dist.Janjgir, Champa, Chattisgarh (Tapering Linkage) SECL All milestones. 146 Meja TPP (Joint venture of NTPC and UPRVUNL), Distt. Allahabad, UP (A unit Bulk Tendring SECL All milestones. Change of name is under process at SECL. of Meja urja Nigam pvt. Ltd. - MUNPL)

19 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), Nabha Power Ltd., Bhawanigarh, Nabha Road, Nabha, Punjab ( 1&) SECL All milestones. Only 1 unit is covered in the MOC letter upto Neeraj Power Pvt. Ltd., Village Harinbhatta, Post & Block Simga, Dist. Raipur (CG) (Bio-Mass Plant) SECL All milestones within validity period of LOA. As per CL directives, balance of minimum CG for Rs..5 crs. required for PPs was asked, which has not been submitted. Matter is subjudice. Matter subjudice 149 Patel Energy Limited (an SPV of Patel Engineering Limited), Bhavnagar, Gujrat SECL * All milestones not within overall LOA validity. LOA cancellation/withdrawal and CG plus Addl.CG forfieted. CG Forfeited and matter subjudiced. 150 R.K.M. Powergen Private Ltd., Uchapinda Metter regarding approval for change in capacity from 1x350 MW to 1x360 TPP (Phase-1), Chattisgarh (1x350 MW) SECL MW has been referred by CL to MOC vide letter CL/CMO/475 (New (-1) Pol)/866 dated R.K.M.Powergen Pvt. Ltd., Janjgir, Champa, Chhattisgarh ( 90% level on permanent basis for 500 MW & on tapering basis for 550 MW) (, 3 & 4) SECL Matter regarding approval for change in capacity from 1x350 MW to 1x360 MW has been referred by CL to MOC vide letter CL/CMO/475 (New Pol)/866 dated , clarification on which is required by SECL : V 15 Raj West Power Limited of JSW Energy Limited, Bhadresh, Barmer, Rajasthan (Tapering upto March'1) SECL 540* * LOA has been terminated and CG+ACG has been refunded. LoA terminated 153 Real Power Private Limited (Formerly NR Power & Steel Pvt. Ltd.), Khamhardin, Sargaon, Pathariya, Mungeli, Distt: Bilaspur, CG SECL All milestones except COD & synchronization. 154 Shree Singaji TPP (Formerly Malwa Thermal Power Station), MPPGCL, Vill Purni, Distt. Khandwa, MP ( 1&) SECL FSA yet to be effective Sipat TPS (Stage-) ( 1, & 3), Bilaspur, Chhatisgarh / & SECL For the of for First unit of 1X All milestones except COD & synchronization MOU signed

20 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), SKS Powergen (Chhattisgarh) Ltd. (SPV of M/s. SKS spat and Power Ltd.), Dist: Raigarh, Chhattisgarh (4x300 MW of which LoA under NCDP issued for 0 MW, 90% level for 630 MW on permanent basis & 350 MW on tapering basis) ( 1, and 3) SECL ice for cancellation was issued on As per SLC (LT) dated , no coercive action is to be taken till the issue regarding land acquisition (deficient milestone) is examined in next SLC (LT) and resolved. They have applied to MOC for approval in reduction in land required vide letter Nil dated ice issued for cancellation. 157 SKS Powergen (Chhattisgarh) Ltd. (SPV of M/s. SKS spat and Power Ltd.) (Phase- 1) Dist.Raigarh, Chattisgarh (1x0 MW) ( 4) SECL All milestones except COD & synchronization. 158 Sudha Agro Oil and Chemical ndustry Ltd, Bio-Mass Co-gen power plant, Mohatarai. Semartal Belha, Bilaspur. CG SECL / All milestones. 159 Suratgarh TPS, RRVUNL), Suratgarh Thermal Power Station, Riyanwali, Suratgarh, Rajasthan ( 6) SECL 50 15/ V 160 TRN Energy Pvt. Ltd., Vill. Paraghat & Beltukri, Dist: Bilaspur, Chhattisgarh SECL All milestones except COD & synchronization. 161 Ukai TPS (Extension -6) Gujarat, Songadh, Gujarat (Tapering) SECL achievement is subject to submission of Addl. CG. LOA Still valid 16 Vandana Vidhyut Limited, Vill: Chhuri, Salora, Tehsil: Kathgora, Distt: Korba, CG ( 1&) (Tapering) SECL All milestones except COD & synchronization deal Energy Projects Ltd., Bela, Nagpur, Maharashtra (MPP) ( 1) WCL and PPA not submitted. COD not

21 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), Jinbhuvish Power Gen. Pvt Ltd. Bijora, Mahagaon, Dist Yavatmal, Maharashtra & WCL LoA issued for x 50 MW on 7/ vide letter dated requested to enhance the capacity to x 300 MW. WCL forwarded the application to MoP vide letter dated 0/ MoP after expiry of the LoA have conveyed no objection for enhancement in capacity vide their letter dated As such the capacity in the LoA remained as x 50 MW at the time of expiry of LoA. during the validity of of LoA had submitted documents towards achievement of milestones for both x 50 MW and x 300 MW. As there was no response from MoP in the matter of enhancement of capacity the LoA capacity remained as x 50 MW. The unit was intimated vide letter dated non achievement of milestones and was requested to submit proper documents within the validity period of LoA as well as submit additional CG of Rs 8.07,03,600/-. The unit submitted further documents and additional CG of Rs 4,03,51,800. filed writ petition in the Ho'ble court of Bombay Nagpur bench, Nagpur prior to expiry of LoA. WCL issued notice under clause of the LoA on The unit withdrawn the writ petition on vide letter dated have advised not to take any coercive action till such time the matter is decided after receipt of comments from WCL & CL.WCL vide letter dt submitted the comments to MOC. MOC vide letter dt forwarded the comments of WCL to M/s Jinbhuvish Power Generation Co.Pvt.Ltd. ntimating that the position explained by WCL is in contradictory to the position intimated to MOC by the company and requested to furnish their response on the comments of WCL. Considering the documents submitted by the unit for X50 MW capacity within the validity period of the LoA, the unit failed to achieve number of milestones. Even if documents submitted within the validity period of the LoA is considered for x 300 MW, the unit failed to submit additional CG and achieve milestones related to Approval of nvestment Decision, DPR/ TFR, Land Acquisition. Environment Clearance, Forest Clearance and Commitment of equity investment. Extension granted in meeting held on for submitting Environment Clearance upto 1 or submission of EC whichever is earlier, subject to achievement of all other milestones. Action as per the decision of meeting of is under process. advised not to take any coercive action 165 Aparna nfraenergy, Kawathala, Chimur, Dist Chandrapur Maharashtra & WCL 50 16/ Delayed submission of documents for Financial Closure but not submitted additional CG. Financial closure document shows sponsor's Gammon nfrastructure Projects Limited and/or its subsidiary and/or associate. Sponsor's funding equity requirement of Rs 3765 million. Environmental Clearance not. Forest clearance Milestone not. Milestone for Water allocation not also failed to submit additional CG. vide letter dated have advised not to take any coercive action till such time the matter is decided after receipt of comments from WCL & CL.WCL vide letter dt have submitted the comments to MOC. MOC vide letter dt have forwarded the comments of WCL to M/s Aparna nfraenergy ndia Pvt.Ltd. ntimating that the position explained by WCL is in contradictory to the position intimated to MOC by the company and requested to furnish their response on the comments of WCL. advised not to take any coercive action 166 Bhadravati TPP of Central ndia Power Co. Ltd., Bhadravati, Dist. Chandrapur, Maharashtra & WCL 660 6/10/ * not. in the meeting held on decided for cancellation of linkage/loa. LoA cancelled/withdrawan, CG forfeited. filed writ petition in the Hon'ble court of Bombay Nagpur Bench Nagpur hearing on which is pending. CG Forfeited and matter subjudiced. 167 Gaps Power & nfrastructure Pvt. Ltd., Shendra, MDC, Aurangabad, Maharastra WCL * Less CG submitted requested to enhance CG to Rs..5. Crores. submitted LoA canceled/ withdrawn. LoA cancelled/ withdrawn

22 Status of LOAs issued to power utilities by CL sources (As on ) (Provisional) /Plant Name LOA ssuance LoA s ssued FSA s MoU s Plant/ (s), Gupta Energy Pvt. Ltd., Usegaon, Chandrapur, Nagpur, Maharastra WCL LoA issued to M/s Gupta Energy Pvt. Ltd on ratified change of name to M/s Gupta Energy Ltd. on. Milestone (Approval of nvestment decision), Milestone 4 (Land), Milestone 5 (Envi. clearance), and Milestone 8 (Equity nvestment) are to be. Additional CG sought not submitted. again changed name to M/s Gupta Energy (P) Ltd as per application dated which had been agreed to by WCL and consumer was asked to submit documents towards achievement of milestones in the changed name. No document submitted nor Additional CG sought for non achievement of Milestone & 4 in the earlier name have been submitted. MOC vide letter dt have requested to await the outcome of decision of for Power before taking a view on cancellation of LoA or forfeiting of BG etc. in respect of this case. M/s Gupta Energy Pvt.Ltd. Vide letter dt have represented for acceptance of milestone documents for 70 MW power plant and condone inadvertent delay to achieve milestones in target time and allow to submit additional CG. Extension granted in meeting held on for submitting Environment Clearance/Forest Clearance upto 1 or submission of EC/FC whichever is earlier, subject to achievement of all other milestones. Varification as per the decision is under process. advised not to take any coercive action 169 ndiabulls Amravati TPP, Nandgaonpet, Dist Amravati Maharashtra, ndiabulls Power Ltd., Phase- ( 1&) WCL 1350* Achieved all milestones. PPA not submitted : V-V 170 ndiabulls Nasik TPP of M/s ndia Bulls Realtech Ltd., Sinnar Dist Nasik, Maharashtra Phase- ( 1-5) WCL 1350* Milestone. PPA not submitted : V-V 171 Maharashtra Airport Development Authority Ltd. (MADC) of Abhijit MADC Nagpur Energy (P) Limited WCL Milestone. 17 MAHGENCO (Tapering Linkage) Bhusawal 6 and Parli WCL All milestones. Expected COD of Parli-8 is July 013 & Bhushawal-6 is March 017. Both the units linked to Machhakata coal block, Normative Date of Production of which is shown by CCO as NTPC, Mouda STPS, Stage-, Mouda, Distt: Nagpur, Maharastra ( ) WCL Synchronisation and COD to be Satpura TPS( Extension), Sarni Dist. Betul, MP ( 10&11) & WCL 500 1/ , submitted Option Letter for Surrender of mported Coal. COD to be X-X 175 Vidarbha ndustries Power Ltd., MDC ndustrial Area, Butibori, Nagpur ( 1) WCL 300 1/ PPA not submitted Wardha Power Ltd, Warora, MDC, Dist. Chandrapur,Maharastra (540 MW) ( 1,, 3 &4) WCL FSA Executed on Cost Plus basis V on cost plus basis TOTAL